Loading...
Serving Delano, CA and surrounding areas. (661) 553-7796
Effective date: January 1, 2026
By accessing the website at delanosunrooms.com or by engaging the services of Delano Sunrooms and Patios, you agree to be bound by these Terms and Conditions. If you do not agree to these terms, please do not use our website or services.
These terms apply to all visitors to our website and to all customers who receive a written estimate, sign a contract, or otherwise engage Delano Sunrooms and Patios for construction or installation services.
Delano Sunrooms and Patios provides residential sunroom construction and installation services in Delano, CA and surrounding communities. Services include but are not limited to sunroom additions, four season and three season sunrooms, patio enclosures, screen room installation, patio-to-sunroom conversions, deck-to-sunroom conversions, solarium installation, patio cover installation, and related construction work.
All work is performed by licensed personnel and in compliance with applicable building codes. Services are provided only within our established service area. We reserve the right to decline any project at our discretion.
Written estimates provided by Delano Sunrooms and Patios are based on information gathered during an on-site assessment and are valid for 30 days from the date of issue unless otherwise stated. Estimates are not final contracts.
Final pricing is confirmed in the written contract signed by both parties before work begins. Pricing may change if the scope of work changes, if site conditions differ materially from what was assessed, or if you request changes to materials or design after the contract is signed. Any change in scope that affects cost will be communicated to you in writing before additional work proceeds.
Permit fees charged by local authorities are separate from our labor and material costs and will be itemized in the estimate. Actual permit fees are set by the City of Delano Building Division and may differ from the estimate if fee schedules change before permits are issued.
Project start dates are estimates and are subject to permit approval timelines, weather conditions, and subcontractor availability. We will communicate any changes to your scheduled start date as soon as we are aware of them.
If you need to cancel or postpone a project after signing a contract, please notify us in writing as soon as possible. Cancellation policies, including any fees for work already performed or materials already ordered, are outlined in your signed contract. Deposits for materials that have already been ordered may be non-refundable.
We reserve the right to reschedule work due to unsafe weather conditions, permit delays, or circumstances beyond our control. We will not charge additional fees for rescheduling due to these circumstances.
Payment terms are outlined in your signed contract. Typical arrangements require a deposit before work begins, progress payments tied to project milestones, and a final payment upon project completion and customer walkthrough.
Final payment is due upon substantial completion of the work, unless otherwise agreed in writing. Failure to make timely payments may result in a pause in work until the account is brought current. Accounts that remain unpaid beyond the due date stated in the contract may be subject to interest charges or collection action as permitted under California law.
Accepted payment methods are specified in your contract. We do not accept payments arranged through third-party apps or services not listed in the contract.
Delano Sunrooms and Patios will apply for all required building permits on behalf of the customer unless otherwise agreed in writing. The customer grants Delano Sunrooms and Patios authorization to submit permit applications and to communicate with the City of Delano Building Division on their behalf.
The customer is responsible for ensuring clear access to the project site for all required city inspections. Delays in access that result in failed inspections or re-inspection fees are the responsibility of the customer.
Delano Sunrooms and Patios warrants that all work will be performed in a professional and workmanlike manner in accordance with applicable building codes and industry standards. Specific warranty terms, including duration and what is covered, are outlined in your signed contract.
Warranties do not cover damage resulting from misuse, neglect, unauthorized modifications, acts of nature, or normal wear and tear. Manufacturer warranties on materials such as windows, glass panels, and roofing products are separate from our workmanship warranty and are subject to the manufacturer's own terms.
The warranty is void if the customer has not made full payment as required by the contract.
To the fullest extent permitted by law, Delano Sunrooms and Patios's total liability for any claim arising out of or related to our services shall not exceed the total amount paid by the customer for the specific project to which the claim relates.
We are not liable for indirect, incidental, consequential, or punitive damages, including lost use of your property, loss of income, or costs associated with temporary housing during construction. These exclusions apply even if we have been advised of the possibility of such damages.
Nothing in these terms limits our liability for personal injury caused by our negligence, for fraud or fraudulent misrepresentation, or for any matter where it would be unlawful to limit or exclude liability.
The content on our website is provided for general informational purposes only. We make reasonable efforts to keep information current and accurate, but we do not warrant that the website is free from errors or that it will be available without interruption.
You may not use our website for any unlawful purpose or in any way that could harm our business, our customers, or third parties. We reserve the right to restrict access to the website at any time without notice.
If a dispute arises between you and Delano Sunrooms and Patios, we ask that you contact us first so we can attempt to resolve it directly. Most issues can be resolved quickly through direct communication.
If a dispute cannot be resolved informally, both parties agree to attempt to resolve the matter through mediation before initiating formal legal proceedings. Mediation costs will be shared equally unless otherwise agreed.
If mediation does not resolve the dispute, either party may pursue their legal remedies. Nothing in this section limits your right to contact the California Contractors State License Board (CSLB) if you have a complaint about licensed contractor work.
These Terms and Conditions are governed by the laws of the State of California, without regard to conflict of law principles. Any legal proceedings arising from these terms shall be brought in a court of competent jurisdiction in Kern County, California.
We may update these Terms and Conditions from time to time. When we do, we will revise the effective date at the top of this page. We encourage you to review this page periodically. Continued use of our website or services after changes are posted constitutes your acceptance of the updated terms.
If you have questions about these Terms and Conditions, please contact us:
Delano Sunrooms and Patios
1106 Belmont St, Delano, CA 93215